In this case, a prospective tenant, Mears, entered into an agreement for a lease for two blocks of student flats on completion of the build. The agreement contained a clause stating that if a certificate of practical completion had not been issued on the blocks by 18 September 2018, Mears could give notice of termination. The lease prohibited the reduction of room sizes by more than 3% from those shown on the contract drawings.
Breach of agreement
In August 2018, Mears complained that the room sizes of the buildings were more than 3% smaller than as shown in the contract drawings, in breach of the terms of the agreement. Despite Mears’ complaints, Costplan indicated that it intended to issue a certificate of practical completion.
Mears sued and obtained an interlocutory injunction restraining Costplan from issuing a certificate of practical completion until trial. In addition Mears sought declarations including that the reduction in size was a material breach of the agreement, which would prevent practical completion.
Breach of contract vs practical completion
At first instance, although the judge found that the rooms had been built 3% smaller but refused to grant Mears the declarations sought. On appeal, the judge agreed with the decision at first instance. The appeal court judge made a distinction between a breach of the contract (that the rooms were more than 3% smaller) and whether the building could be certified as practically complete. Whether or not a breach of contract would preclude practical completion was a matter of fact and degree in each case. The judge stated that it would be commercially unworkable if every departure from contract drawings resulted in the prevention of practical completion regardless of the nature and extent of departure.
- the building can be used as intended; and
- all items of work have been completed and all defective work has been remedied (other than trifling defects).
It is important to note that the judge found that the fact that a defect is irremediable does not preclude practical completion. The judgement contains a strong streak of pragmatism throughout, the judge noting that practical completion is easier to identify than to define. For example, just because a build is capable of being inhabited does not necessarily mean that it is practically complete regardless of the nature and extent of remaining work.
This decision provides welcome assistance to developers in providing certainty that not every tiny departure from plans will be enough to preclude completion certification. However, the decision will also provide relief to prospective tenants showing that defects of sufficient severity will preclude practical completion despite the fact that the building is technically habitable.
*Mears Limited v Costplan Services (South East) Limited & Ors  EWCA Civ 502.
Disclaimer: While we do all that is possible in terms of ensuring its accuracy, this blog contains general information only. Nothing in these pages constitutes legal advice. You need to consult a suitably qualified lawyer from the firm on any specific legal problem or matter.
Other Property Development Articles
Court takes pragmatic approach in its first consideration of Practical Completion in construction contracts for 50 years.
The High Court has put climate change considerations firmly on the map by clearly stating that efforts to mitigate climate change, via optimal functioning of solar panels, are material considerations when it comes planning permission [...]
The background to this case provides sober reading for any landowners of vacant sites. In this instance, around 2000 tonnes of waste including food and medical waste was deposited on Newark’s vacant land without [...]
Anybody entrusted with selling property on the behalf of a lender can take comfort in the robust approach shown by the Court.
Barr Ellison acted in a successful application to modify a restrictive covenant for a developer which otherwise prevented their redevelopment of a site in Cambridge.
Restrictive covenants can be a headache for developers who have otherwise found the perfect piece of land on which to carry out their dream development.
It is always preferable for leases to contain express reservations to alter, build and erect scaffolding in favour of a landlord who might want to develop at some point in the future.
A Court of Appeal decision serves as a warning to developers of the dangers of proceeding with developments in breach of a restrictive covenant.
It is a strict requirement that a party needs to be in compliance with all conditions precedent before serving a notice to complete a property transaction.
Appellants would be well advised to take care when introducing new evidence to a planning appeal, ensuring that it is available in good time for public inspection, usually via the local authority’s website.
The Supreme Court held that the landlord’s intention to demolish or reconstruct must be independent of the tenant’s claim for a new tenancy and not conditional upon it.
Barr Ellison once again sponsored the Innovation of the Year category at this year’s Cambridge Property Awards.
A landmark case has clarified the scope of an action for nuisance based on the presence of Japanese knotweed.
Overage disputes: Court likely to strictly and literally interpret the provisions of an overage agreement between experienced developers.
In recent years, a subculture has developed that has caused property owners and property developers particular concern. Known as urban exploration or urbex ...
The Court of Appeal has found that a term to deal with planning permissions can be implied in a construction contract ...
Developers will welcome recent guidance on the modification of restrictive covenants …
Where planning permission is granted, reasons for the grant of such planning permission may be required to be given, even where there is no statutory duty to do so.
There is an emerging trend towards local authorities refusing planning even where they cannot demonstrate adequate housing supply ...
The Environmental Impact Assessment Directive updates the EU’s legislation on environmental impact assessments with a substantial refresh of the EIA Scheme.